1987第3版-YB黄皮书-电气与机械工程合同条件英文Word文档格式.doc
《1987第3版-YB黄皮书-电气与机械工程合同条件英文Word文档格式.doc》由会员分享,可在线阅读,更多相关《1987第3版-YB黄皮书-电气与机械工程合同条件英文Word文档格式.doc(64页珍藏版)》请在冰豆网上搜索。
![1987第3版-YB黄皮书-电气与机械工程合同条件英文Word文档格式.doc](https://file1.bdocx.com/fileroot1/2022-10/12/8951aa76-29cd-4d3a-a506-d9c2f31c98f7/8951aa76-29cd-4d3a-a506-d9c2f31c98f71.gif)
CommencementDate
Sub-Clause1.1.1.(i)
ThedateforcommencementoftheWorksis.
TheEmployer
Sub-Clause1.1.12.
TheEmployeris.
TheEngineer
Sub-Clause1.1.15.
TheEngineeris.
TimeforCompletion
Sub-Clause1.1.1.35.
TheTimeforCompletionisdaysfromtheCommencementDate.
Contractor'
sProfit
Sub-Clause1.6
Thepercentagetocoverprofitentitlement,whereappropriate,is%.
RulingLanguage
Sub-Clause5.1
Theversioninlanguage(rulinglanguage)shallprevail.
DaytoDayCommunications
Sub-Clause5.2.
Thelanguagefordaytodaycommunicationsis.
ProgrammetobeFurnished
Sub-Clause12.1.
TheProgrammemustbesubmittedintheformof.
Electricity,Water,GasandOtherServices
Sub-Clause14.3.
SuppliesontheSiteare:
.
a.Electricity:
.
b.Water:
.
c.Gas:
.
d.Otherservices:
.
Employer'
sEquipment
Sub-Clause14.4.
ThefollowingEmployer'
sequipmentisavailableforusebytheContractorundertheEmployer'
soperation:
.
WorkingHours
Sub-Clause18.3
Thenormalworkinghoursare.
DelayinCompletion
Sub-Clause27.1
FailuretomeettheTimeforCompletionentitlestheEmployertoreductioninContractPriceasfollows:
Percentageperday%
Maximum%
ProlongedDelay
Sub-Clause27.2.
MaximumamountrecoverablefromtheContractorbytheEmployer:
.
TermsofPayment
Sub-Clause33.1.
InadditiontotheprovisionsunderClause33,thetermsofpaymentshallbe:
PaymentinForeignCurrencies
Sub-Clause35.1.
Paymentinforeigncurrenciesshallbearrangedasfollows:
.
RatesofExchange
Sub-Clause35.3.
TheratesofexchangeforthepurposeoftheContractare:
.
PaymentagainstProvisionalSums
Sub-Clause36.4.(b)
ThepercentagetobeappliedtoProvisionalSumsshallbe%
MaximumLiability
Sub-Clause42.2.
ThemaximumliabilityoftheContractortotheEmployershallbe.
InsuranceofWorks
Sub-Clause43.1.
ThededuciblelimitsintheinsurancecoveroftheWorksshallnotexceed.
Sub-Clause43.1.(a)
Theadditionalriskstobeinsuredare:
.
ThirdPartyLiability
Sub-Clause43.3.
TheamountofinsuranceagainstthirdpartyliabilitytakenoutbytheContractorshallnotbelessthan:
.
PaymentonTerminationforEmployer'
sDefault
Sub-Clause46.3.
TheadditionalamountpayablebytheEmployeronterminationshallnotexceed:
.
Labour,MaterialsandTransport
Sub-Clause47.1.
Themethodofcalculatingadjustmentsforchangesincostsshallbe:
NoticestoEmployerandEngineer
Sub-Clause49.2.
TheaddressoftheEmployerfornoticesis:
.
TheaddressoftheEngineerfornoticesis:
.
ApplicableLaw
Sub-Clause51.1.
Theapplicablelawislaw.
ProceduralLawforArbitration
Sub-Clause51.2.
Theprocedurallawforarbitrationis
LanguageandPlaceofArbitration
Sub-Clause51.3.
Thelanguageofarbitrationislanguage.
Theplaceofarbitrationis.
PARTI:
GENERALCONDITIONS
DefinitionsandInterpretations
Definitions
1.1
IntheContract(ashereinafterdefined)thefollowingwordsandexpressionsshallhavethemeaningsherebyassignedtothem:
1.1.1
"
CommencementDate"
meanswhicheveristhelatestof:
i)thedatespecifiedinthePreambleasthedateforcommencementoftheWorksorthedatewhentheContractorreceives:
ii)suchpaymentinadvanceofthecommence