工程建设合同范本英文.docx

1、工程建设合同范本英文篇一:中英文对照-工程施工合同范本工程施工合同contract合同编号( contract no、 ): 签订日期( date ):发包方(简称甲方)party a:承包方(简称乙方):party b:根据中华人民共与国合同法以及其她有关法律法规规定得原则,结合本工程得具体情况,甲、乙双方在平等、自愿、协商一致得基础上达成如下协议,共同遵守。according to “p、r、c contract law”, and other relevant laws and regulations to the specific circumstances of this proje

2、ct, parties a and b have hereby equally and voluntarily entered into the following agreement executed on the basis of mutual respect、1. 工程概况project overview1.1. 工程名称:project name:1.2. 工程地点:project location:1.3. 工程范围:a. 新研发中心与新厂房得网络综合布线系统得施工;b. 数据中心得建设,主要包含:数据中心得装饰工程、电气系统、空调系统、机房闭路监控系统、机房门禁系统、消防系统改造、

3、机柜系统等。project contents:a. the new r & d and new plant construction of network cabling systems;b. data center, mainly includes: data center decoration and electrical systems, air-conditioning systems, cctv systems, access control systems, firefighting system reform, server rack systems、1、4 开工条件:合

4、同生效后,甲方预付款到位与现场具备开工条件。1、5 工程造价:合同工程总造价为￥cny),人民币大写 project cost:total project cost is yuan ( cny )、详细合同价格表见附件报价清单。detailed contract price list see attached quotation list、在详细设计与施工过程中,若工程量发生变化,按合同单价相应调整工程造价;若材质发生变化,按双方商定得补充协议调整工程造价。in the detailed design and construction process, if the project quant

5、ity changes, according to the contract price adjustment project cost; if the material is changed, the supplemental agreement agreed by both parties for adjustment of engineering cost、2、 付款方式terms of payment2、1 由乙方向甲方提供指定帐户、甲方以支票方式或银行转账方式向乙方结算合同款; party b shall provide the designated account to party

6、 a, party a by check or bank transfer to pay the contract payment to party b、2、2 本合同生效后,甲方付给乙方合同总价得40%作为工程预付款,即￥元; after the signing of this contract, party a shall pay to party b 40% of the total contract price as the project advance payment;2、3 数据中心及网络布线系统工程完工并且双方签订工程验收报告后7天以内,甲方付给乙方合同总价得55%,即￥ 元;

7、2、4 工程竣工后3个月内,甲方支付给乙方剩余得合同款,即￥3、 双方职责responsibilities of the parties3、1 甲方职责:responsibilities of party a:a. 及时以书面形式通知乙方本工程具备开工条件得时间;timely written notice to party b the conditions of this project have the time to start;b. 协助乙方办理进驻施工现场所需人员证件、批件等有关手续;to assist party b to enter the construction site pe

8、rsonnel required documents, approval documents and other relevant procedures;c. 为乙方提供现场工程办公室与足够得现场仓库;to provide on-site engineering office and sufficient field warehouse;d. 积极协助乙方施工,协调施工时与各部门得配合,并负责提供工程所需得现场平面图及建筑结构图。actively assist party b construction, coordination with various departments, and re

9、sponsible for providing the needed for the project site plans and architectural drawings、e. 及时按合同规定之付款进度向乙方支付工程款项。timely according to the terms of the contract payment schedule to pay party b project funds、3、2 乙方职责:responsibilities of party b:a. 乙方在工程开始前应组织有关人员研究与熟悉图纸,参与设计交底,安排施工总进度计划并提交给甲方;party b

10、before the project begins shall organize relevant personnel to study and be familiar with drawings, involved in the design work, arrangement of construction general schedule plan and submit to party a;b. 向甲方或项目监理提供所购各种产品、设备得技术资料,接受进场检验;to the party a or project supervision to provide the purchase a

11、variety of products, equipment, technical information, accept entry inspection;c. 遵守甲方或监理方对施工现场得有关规定;abide by the party or the supervision on construction site of the relevant provisions;d. 按时完成乙方所承担得施工任务,保证工程施工质量。4、 施工与工程设计变更construction and engineering design change4、1 乙方在施工中要根据国家颁发得施工验收规范与质量检验标准,

12、以及设计要求进行,要求全部工程达到合格标准。on the construction of party b according to the country issued construction acceptance norms and quality inspection standards, as well as the design requirements, all project achieve the qualified standard、4、2 在施工中,要坚持按照设计文件与施工图纸施工,任何一方不得随意变更设计,如出现窝工、返工与材料损失,以及增加劳动力成本等,由于甲方得原因造

13、成得,损失由甲方承担,由于乙方得原因造成得,损失由乙方承担。during construction, to adhere to the design documents and construction drawings of the construction, any party shall not be arbitrarily changed design, such as the emergence of idleness, rework and loss of material, as well as an increase in labor cost, as the party a

14、s cause, loss borne by the party a, the party b causes, losses shall be borne by party b、4、3 在施工中,若甲方a有变更设计文件得要求,应书面通知乙方;若乙方发现设计文件有错误或严重不合理得地方,也应书面通知甲方,双方商定并修改设计文件与图纸后方可继续施工。during the construction, if the party a to change the design document, shall give a written notice to party b; if party b is f

15、ound the design documents are wrong or serious ueasonable place, should also be written notice to party a, both sides agreed and modify design drawings and documents before it can continue to construction、4、4 在施工过程中,如遇下列情况,需顺延工期,双方应及时进行协商,并通过书面形式确定顺延期限:in the process of construction, in case of the

16、following circumstances, be extended period, both parties shall timely consultations, and through the written form to determine the extension of the time limit:a. 因天灾或人力不能抗拒得原因被迫停工得;because of natural disaster or the manpower irresistible reasons forced shutdown;b. 因甲方提出变更计划或变更施工图而不能继续施工得;because pa

17、rty a proposed changes to the plan or change the construction graph therefore cannot continue construction;c. 乙方不能按期供设备或所供材料或者设备不合规格要求,被迫停工或不能顺利施工得; party b fails to supply equipment or for the materials or equipment of different specifications, was forced to shut down or not smooth construction;5、

18、竣工验收与售后服务final acceptance and after-sales service5、1 乙方必须严格执行隐蔽工程验收制度,凡隐蔽工程完成后,必须经过验收并作好记录(隐蔽工程指墙内、吊顶内得管线施工等)。5、3 工程验收合格后进入质保期。质保期为验收合格之日起12个月。在质保期内,乙方应对系统除人为因素外得所有故障负责免费维修或更换。project after acceptance into the warranty period、 warranty period from the date of acceptance of 12 months、 during the warr

19、anty period, party b shall system in addition to human factors all fault is responsible for free repair or replacement、5、4 在质保期内,乙方做到对甲方求援电话2小时内响应,8小时内抵达现场并着手解决问题。质保期结束后,乙方对系统进行有偿维护。有偿维护得费用由双方协商。during the warranty period, party b shall do to help telephone response within 2 hours, 8 hours to arrive

20、 at the scene and set about solving the problem、 after the end of the warranty period, party b on the system paid maintenance、 paid maintenance costs through consultation by the two parties、6、 技术服务与培训technical service and training6、1 由乙方按技术培训大纲负责对甲方得有关操作人员与维修人员进行使用级培训。通过培训,使甲方得受训人员能掌握系统设备得配置,能进行正确操作

21、与日常维护及一般常见故障排查。接受培训得人员由甲方确定,日期由甲乙双方共同商定。6、2 在保修期内,乙方提供两次上门巡检服务,包括各系统运行状况得查瞧、记录,以及必要得设备维护。during the warranty period, party b shall provide two on-site inspection services, including the status of system view, recording, and the necessary equipment maintenance、篇二:完整工程施工合同 英文版translation:construction

22、contractparty a: (developer)(contractor)this contract is signed by the two parties party a and party b according to the contract law of the peoples republic of china, the contraction law of the peoples republic of china , and other relevant national laws and regulations, as well as the specific natu

23、re of this project、 on the basis of honesty and credit, equality, voluntariness, party a and party b have reached consensus through negotiations and signed this contract、1. project introduction1.1. 1、2 1、3 1、4 the design of construction drawings:2. nature of contracting3. construction period4. quali

24、ty of project5. contract amount5.1. 5、26. final audit of the project6、1 the condition and steps for party a pay the project funds to party b:6、2 6、3 party b shall submit to party a equivalent invoice before party as each period payment, otherwise, party a can refuse to pay until the receiving of the

25、 party bs invoice、6、4 the invoice provided by party b should be valid、 any falls invoice provided by party b which are found by relevant office, the party b should not only provide the valid invoice to party a, but also bear the responsible caused by the invalid invoice、7. variation of design and vi

26、sa8. 1during the process of the project, any contract list, technology checking list ( not include the variation, addition, substitution, and reduction on the drawings and project fee) concerning about this project shall only be regarded as effective with the confirmation of the representative party

27、 a in writing、7、2 any variation notice list, technology checking list, contract list, technology checking list ( include the drawings design) concerning about this project shall only be regarded as effective with the confirmation of the seal of party a、9. 4party b shall take full responsibility for

28、any loss caused by delaying for more than days applying for extension vise from party a changed design、10. acceptance and final audit of the project10.1. acceptance of the projectworking days after receiving the notification、8、1、2party b shall be responsible for the re-inspection cost, and the proje

29、ct periodshall not be extended、10.2. final audit of the projectif the result of re-inspection has passed acceptance standards, party b shall submit the audit report and materials to party a for verification within11. obligations of party a and party b11.1. obligations of party a:as the on-site repre

30、sentative to supervise the fulfillment of contract obligations, to oversee the quality control and check the project progress, and to handle issues such as acceptance and variations and withdraw therepresentative at any time、9、1、2、 design drawings and scheme to party b、9、1、4、party a shall be respons

31、ible for coordinating the relationship with the engining、9、2、2、party b shall observe safetypolicies of on-site management by the state and guangxi , nanning government authorities and shall independently and fully assumes responsible for the loss caused by violation、9、2、4、during construction, party

32、b should make such adjustment to the construction plan and the progress schedule per party as instruction and change-orders、12. agreement on safetyparty b must strictly adhere to the safety and technical standards of construction and infrastructure installation and regulation of china, guangxi zhuang autonomous region, nanning safety standards and other relevant regulations and standards、the construction spot should meet all standards of the peoples