工程建设合同范本英文.docx
《工程建设合同范本英文.docx》由会员分享,可在线阅读,更多相关《工程建设合同范本英文.docx(16页珍藏版)》请在冰豆网上搜索。
![工程建设合同范本英文.docx](https://file1.bdocx.com/fileroot1/2023-6/9/9c62ce0b-6cfc-40ff-9b7b-a8441798a592/9c62ce0b-6cfc-40ff-9b7b-a8441798a5921.gif)
工程建设合同范本英文
篇一:
中英文对照-工程施工合同范本
工程施工合同
contract
合同编号(contractno、):
签订日期(date):
发包方(简称甲方)
partya:
承包方(简称乙方):
partyb:
根据《中华人民共与国合同法》以及其她有关法律法规规定得原则,结合本工程得具体情况,甲、乙双方在平等、自愿、协商一致得基础上达成如下协议,共同遵守。
accordingto“p、r、ccontractlaw”,andotherrelevantlawsandregulationstothespecificcircumstancesofthisproject,partiesaandbhaveherebyequallyandvoluntarilyenteredintothefollowingagreementexecutedonthebasisofmutualrespect、
1.工程概况
projectoverview
1.1.工程名称:
projectname:
1.2.工程地点:
projectlocation:
1.3.工程范围:
a.新研发中心与新厂房得网络综合布线系统得施工;
b.数据中心得建设,主要包含:
数据中心得装饰工程、电气系统、空调系统、机房闭路监控系统、机房门禁系统、消防系统改造、机柜系统等。
projectcontents:
a.thenewr&dandnewplantconstructionofnetworkcablingsystems;
b.datacenter,mainlyincludes:
datacenterdecorationandelectricalsystems,air-conditioningsystems,cctvsystems,accesscontrolsystems,firefightingsystemreform,serverracksystems、
1、4开工条件:
合同生效后,甲方预付款到位与现场具备开工条件。
1、5工程造价:
合同工程总造价为¥cny),人民币大写projectcost:
totalprojectcostisyuan(cny)、
详细合同价格表见附件报价清单。
detailedcontractpricelistseeattachedquotationlist、
在详细设计与施工过程中,若工程量发生变化,按合同单价相应调整工程造价;若材质发生变化,按双方商定得补充协议调整工程造价。
inthedetaileddesignandconstructionprocess,iftheprojectquantitychanges,accordingtothecontractpriceadjustmentprojectcost;ifthematerialischanged,thesupplementalagreementagreedbybothpartiesforadjustmentofengineeringcost、
2、付款方式
termsofpayment
2、1由乙方向甲方提供指定帐户、甲方以支票方式或银行转账方式向乙方结算合同款;partybshallprovidethedesignatedaccounttopartya,partyabycheckorbanktransfertopaythecontractpaymenttopartyb、
2、2本合同生效后,甲方付给乙方合同总价得40%作为工程预付款,即¥元;afterthesigningofthiscontract,partyashallpaytopartyb40%ofthetotalcontractpriceastheprojectadvancepayment;
2、3数据中心及网络布线系统工程完工并且双方签订工程验收报告后7天以内,甲方付给乙方合同总价得55%,即¥元;
2、4工程竣工后3个月内,甲方支付给乙方剩余得合同款,即¥
3、双方职责
responsibilitiesoftheparties
3、1甲方职责:
responsibilitiesofpartya:
a.及时以书面形式通知乙方本工程具备开工条件得时间;
timelywrittennoticetopartybtheconditionsofthisprojecthavethetimetostart;
b.协助乙方办理进驻施工现场所需人员证件、批件等有关手续;
toassistpartybtoentertheconstructionsitepersonnelrequireddocuments,approvaldocumentsandotherrelevantprocedures;
c.为乙方提供现场工程办公室与足够得现场仓库;
toprovideon-siteengineeringofficeandsufficientfieldwarehouse;
d.积极协助乙方施工,协调施工时与各部门得配合,并负责提供工程所需得现场平面图及建筑结构图。
activelyassistpartybconstruction,coordinationwithvariousdepartments,andresponsibleforprovidingtheneededfortheprojectsiteplansandarchitecturaldrawings、
e.及时按合同规定之付款进度向乙方支付工程款项。
timelyaccordingtothetermsofthecontractpaymentscheduletopaypartybprojectfunds、
3、2乙方职责:
responsibilitiesofpartyb:
a.乙方在工程开始前应组织有关人员研究与熟悉图纸,参与设计交底,安排施工总进度计划并提交给甲方;
partybbeforetheprojectbeginsshallorganizerelevantpersonneltostudyandbefamiliarwithdrawings,involvedinthedesignwork,arrangementofconstructiongeneralscheduleplanandsubmittopartya;
b.向甲方或项目监理提供所购各种产品、设备得技术资料,接受进场检验;
tothepartyaorprojectsupervisiontoprovidethepurchaseavarietyofproducts,equipment,technicalinformation,acceptentryinspection;
c.遵守甲方或监理方对施工现场得有关规定;
abidebythepartyorthesupervisiononconstructionsiteoftherelevantprovisions;
d.按时完成乙方所承担得施工任务,保证工程施工质量。
4、施工与工程设计变更
constructionandengineeringdesignchange
4、1乙方在施工中要根据国家颁发得施工验收规范与质量检验标准,以及设计要求进行,要求全部工程达到合格标准。
ontheconstructionofpartybaccordingtothecountryissuedconstructionacceptancenormsandqualityinspectionstandards,aswellasthedesignrequirements,allprojectachievethequalifiedstandard、
4、2在施工中,要坚持按照设计文件与施工图纸施工,任何一方不得随意变更设计,如出现窝工、返工与材料损失,以及增加劳动力成本等,由于甲方得原因造成得,损失由甲方承担,由于乙方得原因造成得,损失由乙方承担。
duringconstruction,toadheretothedesigndocumentsandconstructiondrawingsoftheconstruction,anypartyshallnotbearbitrarilychangeddesign,suchastheemergenceofidleness,reworkandlossofmaterial,aswellasanincreaseinlaborcost,asthepartyascause,lossbornebythepartya,thepartybcauses,lossesshallbebornebypartyb、
4、3在施工中,若甲方a有变更设计文件得要求,应书面通知乙方;若乙方发现设计文件有错误或严重不合理得地方,也应书面通知甲方,双方商定并修改设计文件与图纸后方可继续施工。
duringtheconstruction,ifthepartyatochangethedesigndocument,shallgiveawrittennoticetopartyb;ifpartybisfoundthedesigndocumentsarewrongorseriousueasonableplace,shouldalsobewrittennoticetopartya,bothsidesagreedandmodifydesigndrawingsanddocumentsbeforeitcancontinuetoconstruction、
4、4在施工过程中,如遇下列情况,需顺延工期,双方应及时进行协商,并通过书面形式确定顺延期限:
intheprocessofconstruction,incaseofthefollowingcircumstances,beextendedperiod,bothpartiesshalltimelyconsultations,andthroughthewrittenformtodeterminetheextensionofthetimelimit:
a.因天灾或人力不能抗拒得原因被迫停工得;
becauseofnaturaldisasterorthemanpowerirresistiblereasonsforcedshutdown;
b.因甲方提出变更计划或变更施工图而不能继续施工得;
becausepartyaproposedchangestotheplanorchangetheconstructiongraphthereforecannotcontinueconstruction;
c.乙方不能按期供设备或所供材料或者设备不合规格要求,被迫停工或不能顺利施工得;partybfailstosupplyequipmentorforthematerialsorequipmentofdifferentspecifications,wasforcedtoshutdownornotsmoothconstruction;
5、竣工验收与售后服务
finalacceptanceandafter-salesservice
5、1乙方必须严格执行隐蔽工程验收制度,凡隐蔽工程完成后,必须经过验收并作好记录(隐蔽工程指墙内、吊顶内得管线施工等)。
5、3工程验收合格后进入质保期。
质保期为验收合格之日起12个月。
在质保期内,乙方应对系统除人为因素外得所有故障负责免费维修或更换。
projectafteracceptanceintothewarrantyperiod、warrantyperiodfromthedateofacceptanceof12months、duringthewarrantyperiod,partybshallsysteminadditiontohumanfactorsallfaultisresponsibleforfreerepairorreplacement、
5、4在质保期内,乙方做到对甲方求援电话2小时内响应,8小时内抵达现场并着手解决问题。
质保期结束后,乙方对系统进行有偿维护。
有偿维护得费用由双方协商。
duringthewarrantyperiod,partybshalldotohelptelephoneresponsewithin2hours,8hourstoarriveatthesceneandsetaboutsolvingtheproblem、aftertheendofthewarrantyperiod,partybonthesystempaidmaintenance、paidmaintenancecoststhroughconsultationbythetwoparties、
6、技术服务与培训
technicalserviceandtraining
6、1由乙方按技术培训大纲负责对甲方得有关操作人员与维修人员进行使用级培训。
通过培训,使甲方得受训人员能掌握系统设备得配置,能进行正确操作与日常维护及一般常见故障排查。
接受培训得人员由甲方确定,日期由甲乙双方共同商定。
6、2在保修期内,乙方提供两次上门巡检服务,包括各系统运行状况得查瞧、记录,以及必要得设备维护。
duringthewarrantyperiod,partybshallprovidetwoon-siteinspectionservices,includingthestatusofsystemview,recording,andthenecessaryequipmentmaintenance、篇二:
完整工程施工合同英文版
translation:
constructioncontract
partya:
(developer)
(contractor)
thiscontractissignedbythetwopartiespartyaandpartybaccordingtothecontractlawofthepeople’srepublicofchina,thecontractionlawofthepeople’srepublicofchina,andotherrelevantnationallawsandregulations,aswellasthespecificnatureofthisproject、onthebasisofhonestyandcredit,equality,voluntariness,partyaandpartybhavereachedconsensusthroughnegotiationsandsignedthiscontract、
1.projectintroduction
1.1.1、21、31、4thedesignofconstructiondrawings:
2.natureofcontracting
3.constructionperiod
4.qualityofproject
5.contractamount
5.1.5、2
6.finalauditoftheproject6、1theconditionandstepsforpartyapaytheprojectfundstopartyb:
6、26、3partybshallsubmittopartyaequivalentinvoicebeforepartya’seachperiodpayment,otherwise,partyacanrefusetopayuntilthereceivingofthepartyb’sinvoice、
6、4theinvoiceprovidedbypartybshouldbevalid、anyfallsinvoiceprovidedbypartybwhicharefoundbyrelevantoffice,thepartybshouldnotonlyprovidethevalidinvoicetopartya,butalsobeartheresponsiblecausedbytheinvalidinvoice、
7.variationofdesignandvisa
8.1duringtheprocessoftheproject,anycontractlist,technologycheckinglist(notincludethevariation,addition,substitution,andreductiononthedrawingsandprojectfee)concerningaboutthisprojectshallonlyberegardedaseffectivewiththeconfirmationoftherepresentativepartyainwriting、
7、2anyvariationnoticelist,technologycheckinglist,contractlist,technologycheckinglist(includethedrawingsdesign)concerningaboutthisprojectshallonlyberegardedaseffectivewiththeconfirmationofthesealofpartya、
9.4partybshalltakefullresponsibilityforanylosscausedbydelayingformorethandaysapplyingforextensionvisefrompartyachangeddesign、
10.acceptanceandfinalauditoftheproject
10.1.acceptanceoftheproject
workingdaysafterreceivingthenotification、
8、1、2partybshallberesponsibleforthere-inspectioncost,andtheprojectperiodshallnotbeextended、
10.2.finalauditoftheproject
iftheresultofre-inspectionhaspassedacceptancestandards,partybshallsubmittheauditreportandmaterialstopartyaforverificationwithin
11.obligationsofpartyaandpartyb
11.1.obligationsofpartya:
astheon-siterepresentativetosupervisethefulfillmentofcontractobligations,tooverseethequalitycontrolandchecktheprojectprogress,andtohandleissuessuchasacceptanceandvariationsandwithdrawthe
representativeatanytime、
9、1、2、designdrawingsandschemetopartyb、
9、1、4、partyashallberesponsibleforcoordinatingtherelationshipwiththeengining、
9、2、2、partybshallobservesafety
policiesofon-sitemanagementbythestateandguangxi,nanninggovernmentauthoritiesandshallindependentlyandfullyassumesresponsibleforthelosscausedbyviolation、
9、2、4、duringconstruction,partybshouldmakesuchadjustmenttotheconstructionplanandtheprogressscheduleperpartyasinstructionandchange-orders、
12.agreementonsafety
partybmuststrictlyadheretothesafetyandtechnicalstandardsofconstructionandinfrastructureinstallationandregulationofchina,guangxizhuangautonomousregion,nanningsafetystandardsandotherrelevantregulationsandstandards、theconstructionspotshouldmeetallstandardsofthepeoples