GCC 1993.docx

1、GCC 1993 GOVERNMENT OF HONG KONG _ GENERALCONDITIONS OF CONTRACTFORCIVIL ENGINEERING WORKS1993 EDITIONGF 501TABLE OF CONTENTSClause Page DEFINITIONS AND INTERPRETATION1(1) Definitions (2) Singular and plural (3) Marginal notes (4) Payment (5) Contract governed by Laws of Hong Kong ENGINEER AND ENGIN

2、EERS REPRESENTATIVE2 Duties and powers of the Engineer and the Engineers Representative ASSIGNMENT AND SUBLETTING3 Assignment 4 Subletting CONTRACT DOCUMENTS5 Documents mutually explanatory 6 Provision of Drawings and Specification 7 Drawings provided by the Contractor for the Works .8 Information n

3、ot to be divulged 9 Use of English language GENERAL OBLIGATIONS10 Extent of Contract 11 Contractor to execute Articles of Agreement 12 Sureties or security 13 Inspection of the Site 14 Sufficiency of Tender 15 Works to be to the satisfaction of the Engineer 16 Programme to be furnished 17 Contractor

4、s superintendence 18 Contractors employees 19 Settingout 20 Safety and security of the Works 21 Care of the Works 22 Damage to persons and property 23 Design responsibility 24 Interference with traffic and adjoining properties 25 Remedy on failure to insure 26 Accident or injury to workmen Clause Pa

5、ge27 Contractor to give notice of injury 28 Patent rights and royalties 29 Giving of notices and payment of fees 30 Compliance with enactments and regulations 31 Notices to be written in English and Chinese 32 Site diary and labour returns 33 Fossils 34 Facilities for other persons 35 Clearance of t

6、he Site on completion 36 Publication of photographs of the Site or the Works 37 Offering gratuities LABOUR38 Site cleanliness 39 Engagement of labour 40 Fair wages 41 Passes MATERIALS, PLANT AND WORKMANSHIP42 Quality of materials, workmanship and tests 43 Access to the Site and places of manufacture

7、 44 Examination of work before covering up 45 Uncovering and making openings 46 Removal of unsatisfactory material and work COMMENCEMENT, COMPLETION AND DELAYS47 Commencement of the Works 48 Possession of the Site 49 Time for completion 50 Extension of time for completion 51 Rate of progress 52 Liqu

8、idated damages for delay 53 Completion of the Works SUSPENSION OF THE WORKS54 Suspension of the Works 55 Suspension lasting more than 90 days MAINTENANCE AND DEFECTS56 Execution of work of repair 57 Temporary reinstatement Clause Page58 Investigating defects MEASUREMENT, VARIATIONS, VALUATIONS AND C

9、LAIMS59 Bill of Quantities and measurement 60 Variations 61 Valuing variations 62 Daywork 63 Disturbance to the progress of the Works 64 Notice of claims PRIME COST, PROVISIONAL AND CONTINGENCY SUMS65 Use of Prime Cost, Provisional and Contingency Sums 66 Varied form of sub-contract and objections t

10、o nomination 67 Accounting of Prime Cost Sums 68 Accounting of Provisional Contingency Sums 69 Payments to Nominated Sub-contractors . 70 Assignment of Nominated Sub-contractors obligations CONSTRUCTIONAL PLANT, TEMPORARY BUILDINGS AND MATERIALS71 Vesting of Constructional Plant and temporary buildi

11、ngs 72 Vesting of materials 73 Removal of Constructional Plant, temporary buildings and materials 74 Hired and hirepurchase Constructional Plant 75 Employers expense in entering into hire or hirepurchase agreement 76 Liability for loss or damage to Constructional Plant 77 Incorporation of certain Cl

12、auses in subcontracts CERTIFICATES AND PAYMENTS78 Contractors interim statements 79 Interim and final payments, Retention Money and interest 80 Maintenance certificate REMEDIES AND POWERS81 Forfeiture 82 Work by person other than the Contractor 83 Recovery of money due to the Employer SPECIAL RISKS

13、AND FRUSTRATION84 Special risks 85 Frustration Clause Page SETTLEMENT OF DISPUTES86 Settlement of disputes NOTICES87 Service of notices DEFAULT OF THE EMPLOYER88 Default of the Employer FLUCTUATIONS89 Contract price fluctuations HEIGHT RESTRICTIONS90 Airport height restrictions INDEX TO GENERAL COND

14、ITIONS OF CONTRACT ClausePageAccess to the Site and places of manufacture 43Access, Contractor to satisfy himself 13(1)Accident or injury to workmen 26Accounting of Prime Cost Sums 67Accounting of Provisional and Contingency Sums 68Additional Drawings and Specifications . 6Additional instructions 15

15、Adjoining properties-interference with 24Agent of the Contractor 17(2)Airport height restrictions 90Alterations, additions and omissions 6062Ambiguities in Contract documents 5Approval not by vesting 72Arbitration 86Articles of Agreement, Contractor to execute 11Assignment of the benefit of hired an

16、d hirepurchase Constructional Plant 74Assignment of the Contract 3Bankruptcy or liquidation of Contractor 81Bills of Quantities 59Bond 12 ClausePageCare of Works, Specialist Works 21Certificate, maintenance 80Certificate of completion of the Works 53Certificates and payment-interim 78 & 79Certificat

17、es, correction 79(5)Cessation of the Employers liability 80(3)Claims, notices and records 64Clearance of the Site on completion 35Commencement, completion and delays 4753Commencement of the Works 47Completion of the Works, certificate for 53Completion of the Works, time for 49Completion of the Works

18、, extension of time for 50Compliance with enactments, regulations 30Conditions of Contract, provisions shall prevail 5Conditions of hire of certain plant 74Constructional Plant, removal 71Contingency Sum 1(1) & 65(1) & 68Contract documents 1(1) &5Contract, extent of 10Contract governed by Laws of Ho

19、ng Kong 1(5)Contract price fluctuations 89 ClausePageContractor not obliged to enter into sub-contract . 66(2)Contractor to give notice of injury 27Contractors employees 18 & 39Contractors design responsibility 7& 65 (3)Contractors interim statements 78Contractors notice of completion of the Works 5

20、3(1)Contractors right of objection to Nominated Sub-contractor . 66(2)Contractors superintendence 17Contractor to execute Articles of Agreement 11Constructional Plant not solely owned by the Contractor 74Correction of certificate 79(5)Cost of samples and tests 42(3)Covering up work, examination befo

21、re 44Covering up work, uncovering 45Crops, damage to 22(1)Damage to the property of the Employer 22(2)Damage to persons and property 22Damage to the Works and Specialist Works 21Damage to the Works and Specialist Works, excepted risks 21(4)Damage to the Works, special risk 84Damages, liquidated 52Da

22、ywork 62 ClausePageDefault of the Employer 88Defective material and work 46 & 56Defects 5658Defect, Contractor to search for, if required 58Definitions and interpretation 1Delay, liquidated damages for 52Design responsibility generally 7, 19, 23, & 65(3)Design responsibility in Prime Cost and Provis

23、ional Sums . 65(3)Direct payment to Nominated Sub-contractors . 69Discrepancies in documents 5Dismissal of Contractors employees 18Disputes, settlement of 86Disturbance to the progress of the Works 63Documents mutually explanatory 5Drawings (1), 6 & 7Duties and powers of the Engineer and of the Engi

24、neers Representative 2Emergency work 82(2)Employers liabilities limited by maintenance certificate 80(3)Enactments and regulations, compliance with 30Engagement of labour 39Engineer and Engineers Representative 2Engineers design responsibility . 19 & 23 ClausePageEnglish language, use of 9Errors in

25、contract documents 5 & 59Errors in quantities 5, 59(3)Errors in settingout 19Estimated quantities, substantial change in 59(4)Examination of work before covering up 44Excepted risks 21(4)Execution of work of repair 56Extension of time, Contractor to give notice 50(1)Extension of time, Contractor to provide particulars 50(3)Extent of the Works 10 & 15Failure to carry out work required, remedy 56(4), 73(2) & 82Fair wages 40Faulty work,