合同资料epc合同条件中英文对照版doc106页精品版Word格式.docx

1、合同1.1.1.1“Contract” means the Contract Agreement, these Conditions, the Employers Requirement, the Tender, and further document （if any） which are listed in the Contract Agreement.“合同”系指合同协议书、本条件、雇主要求、投标书和合同协议书列出的其他文件（如果有）.1.1.1.2“Contract Agreement” means the contract agreement referred to in Sub-C

2、lause 1.6 Contract Agreement, including any annexed memoranda.“合同协议书”系指第1.6款合同协议书中所述的合同协议书及所附各项备忘录.1.1.1.3“Employers requirements” means the document entitled employers requirements, as included in the Contract, and any additions and modifications to such document in accordance with the Contract. Su

3、ch document specifies the purpose, scope, and/or design and/or other technical criteria, for the Works. “雇主要求”系指合同中包括的，题为雇主要求的文件，其中列明工程的目标、范围、和（或）设计和（或）其他技术标准，以及按合同对此项文件所作的任何补充和修改.1.1.1.4“Tender” means the Contractors signed offer for the Works and all other documents which the Contractor submitted

4、therewith （other than these Conditions and Employers Requirements, if so submitted）, as included in the Contract.“投标书”系指包含在合同中的由承包商提交的为完成工程签署的报价，以及随同提交的所有其他文件（本条件和雇主要求除外，如同时提交）.1.1.1.5“Performance Guarantees” and “Schedule of payments” mean the documents so named （if any）, as included in the Contrac

5、t.“履约保证”和“付款计划表”系指合同中包括的具有上述名称的文件（如果有）.1.1.2Parties and Persons各方和人员1.1.2.1“Party” means the Employer or the Contractor, as the context requires.“当事方（或一方）”根据上下文需要，或指雇主，或指承包商。1.1.2.1“Employer” means the person named as employer in the Contract Agreement and the legal successors in title to this perso

6、n.“雇主”系指在合同协议书中被称为雇主的当事人及其财产所有权的合法继承人。1.1.2.3“Contractor” means the person（s） named as contractor in the Contract Agreement and the legal successors in title to this person（s）.“承包商”系指合同协议书中被称为承包商的当事人及其财产所有权的合法继承人。1.1.2.4“Employers Representative” means the person named by the Employer in the Contrac

7、t or appointed from time to time by the Employer under Sub-Clause 3.1 the Employers Representative, who acts on behalf of the Employer.“雇主代表”系指由雇主在合同中指名的人员，或有时由雇主根据第3.1款雇主代表的人员的规定任命为其代表的人员。1.1.2.5“Contractors Representative” means the person named by the Contractor in the Contract or appointed from

8、time to time by the Contractor Sub-Clause 4.3 the Contractors Representative, who acts on behalf of the Contractor.“承包商代表”系指由承包商在合同中指名的人员，或有时由承包商根据第4.3款承包商代表的规定任命为其代表的人员。1.1.2.6“Employers Personnel” means the Employers Representative, the assistants referred to in Sub-Clause 3.2 Other Employers Pers

9、onnel and all other staff, labour and other employees of the Employer and of the Employers Representative; and any other personnel notified to the Contractor, by the Employer or the Employers Representative, as Employers Personnel.“雇主人员”系指雇主代表、第3.2款其他雇主人员中提到的助手、以及雇主和雇主代表的所有其他职员、工人和其他雇员，以及雇主或雇主代表通知承包

10、商作为雇主人员的任何其他人员。1.1.2.7“Contractors Personnel” means the Contractors Representative and all personnel whom the Contractor utilizes on Site, who may include the staff, labour and other employees of the Contractor and of each Subcontractor, and any other personnel assisting the Contractor in the execut

11、ion of the works.“承包商人员”系指承包商代表和承包商在现场聘用的所有人员，包括承包商和每个分包商的职员、工人和其他雇员，以及所有其他帮助承包商实施工程的人员。1.1.2.8“Subcontractor” means any person named in the Contract as a subcontractor, or any person appointed as a subcontractor, for a part of the Works; and the legal successors in title to each of these persons.“分

12、包商”系指为完成部分工程，在合同中指名为分包商、或被任命为分包商的任何人员，以及这些人员财产所有权的合法继承人。1.1.2.9“DAB” means the person or three persons so named in the Contract, or other person（s） appointed under Sub-Clause 20.2 Appointment of the Dispute Adjudication Board or Sub-Clause 20.3 Failure to Agree Dispute Adjudication Board.“DAB（争端裁决委员

13、会）”系指在合同中如此指名的一名或三名人员，或根据第20.2款争端裁决委员会的任命或第20.3款对争端裁决委员会未能取得一致的规定任命的其他人员。1.1.2.10“FIDIC” means the Federation International des Ingenieurs-Conseils, the international federation of consulting engineers. “菲迪克（FIDIC）”系指国际咨询工程师联合会。1.1.3Dates ,Test, Periods and Completion日期、试验、期限和竣工1.1.3.1“Base Date” me

14、ans the date 28 days prior to the latest date for submission of the Tender.“基准日期”系指递交投标书截止前28天的日期。1.1.3.2“Commencement Date” means the date notified under Sub-Clause 8.1 Commencement of Works, unless otherwise defined in the Contract Agreement.“开工日期”系指根据第8.1款工程的开工的规定通知的日期，合同协议书中另有规定的除外。1.1.3.3“Time

15、for Completion” means the time for completing the Works or a Section （as the case may be） under Sub-Clause 8.2 Time for Completion, as stated in the Particular Conditions （with any extension under Sub-Clause 8.4 Execution of Time for Completion）, calculated from the Commencement Date. “竣工时间”系指专用条件中规

16、定的，自开工日期算起，至工程或某分项工程（视情况而定）根据第8.2款竣工时间规定的要求竣工（连同根据第8.4款竣工时间的延长的规定提出的任何延长期）的全部时间。1.1.3.4“Tests on Completion” means the tests which are specified in the Contract or agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 Tests on Completion before the works or a

17、Section （as the case may be） are taken over by the Employer.“竣工试验”系指在合同中规定或双方商定的，或按指示作为一项变更的，在工程或某分项工程（视情况而定）被雇主接收前，根据第9条竣工试验的要求，进行的试验。1.1.3.5“Taking-Over Certificate” means a certificate issued under Clause 10 Employers Taking Over. “接收证书”系指根据第10条雇主接收的规定颁发的证书。1.1.3.6“Tests after Completion” means t

18、he tests （if any） are specified in the Contract and which are carried out under Clause 12 Tests after Completion after the works or a Section （as the case may be） are taken over by the Employer.“竣工后试验”系指在合同中规定的，在工程或某分项工程（视情况而定）被雇主接收后，根据第12条竣工后试验的要求，进行的试验（如果有）。1.1.3.7“Defects Notification Period” mea

19、ns the period for notifying defects in the Works or a Section （as the case may be） under Sub-Clause 11.1 Completion of Understanding Works and Remedying Defects, as stated in the Particular Conditions （with any extension under Sub-Clause 11.3 Extension of Defects Notification Period）, calculated fro

20、m the date on which the Works or Section is competed as certified under Sub-Clause 10.1 Taking Over of the Works and Sections. If no such period is stated in the Particular Conditions, the period shall be one year.“缺陷通知期限”系指专用条件中规定的，自工程或某分项工程（视情况而定）根据第10.1款工程和分项工程的接收的规定证明的竣工日期算起，至根据第11.1款完成扫尾工作和修补缺陷

21、的规定通知工程或分项工程存在缺陷的期限（连同根据第11.3款缺陷通知期限的延长的规定提出的任何延长期）。如果专用条件中没有提出这一期限，该期限应为一年。1.1.3.8“Performance Certificate” means the certificate issued under Sub-Clause 11.9 Performance Certificate.“履约证书”系指根据第11.9款履约证书的规定颁发的证书。1.1.3.9“day” means a calendar day and “year” means 365 days.“日（天）”系指一个日历日，“年”系指365天。1.1

22、.4Money and Payments款项与付款1.1.4.1“Contract Price” means the agreed amount stated in the Contract Agreement for the design, execution and completion of the Works and the remedying of any defects, and includes adjustment （if any） in accordance with the contract.“合同价格”系指在合同协议书中写明的、经商定的工程设计、施工、竣工和缺陷修补的款额

23、，包括以及按照合同做出的调整（如果有）。1.1.4.2“Cost” means all expenditure reasonably incurred （or to be incurred） by the Contractor, whether on or off the Site, including overhead and similar charges, but does not include profit.“成本（费用）”系指承包商在现场内外所发生（或将发生）的所有合理开支，包括管理费用及类似的支出，但不包括利润。1.1.4.3“Final Statement” means the

24、 statement defined in Sub-Clause 14.11Application for Final Payment.“最终报表”系指第14.11款最终付款的申请规定的报表。1.1.4.4“Foreign Currency” means a currency in which part （or all） of the Contract Price is payable, but not the Local Currency.“外币”系指可用于支付合同价格中部分（或全部）款项的当地货币以外的某种货币。1.1.4.5“Local Currency” means the curre

25、ncy of the Country.“当地货币”系指工程所在国的货币。1.1.4.6“Provisional Sum” means a sum （if any） which is specified in the Contract as a provisional sum, for the execution of any part of the Works or for the supply of Plant, Material or services under Sub-Clause 13.5 Provisional Sums.“暂列金额”系指合同中规定作为暂列金额的一笔款额（如果有），

26、根据第13.5款暂列金额的规定，用于工程某一部分的实施，或用于提供生产设备、材料或服务。1.1.4.7“Retention Money” means the accumulated retention moneys which the Employer retains under Sub-Clause 14.3 Application for Interim Payments and pays under Sub-Clause 14.9 Payment of Retention Money.“保留金”系指雇主根据第14.3款期中付款的申请的规定扣留的保留金累计金额，根据第14.9款保留金的支付

27、的规定进行支付。1.1.4.8“Statement” means a statement submitted by the Contractor as part of an application for payment under Clause 14 Contract Price and Payment.“报表”系指承包商根据第14条合同价格和付款的规定提交的作为付款申请的组成部分的报表。1.1.5Works and Goods工程和货物1.1.5.1“Contractors Equipment” means all apparatus, machinery, vehicles and ot

28、her things required for the execution and completion of the Works and remedying of any defects. However, Contractors Equipment excludes Temporary Works, Employers Equipment （if any）, Plant, Materials and any other things intended to form or forming part of the Permanent Works.“承包商设备”系指为实施和完成工程、以及修补任

29、何缺陷需要的所有仪器、机械、车辆和其他物品。但承包商设备不包括临时工程、雇主设备（如果有）、以及拟构成或正构成永久工程一部分的生产设备、材料和其他任何物品。1.1.5.2“Goods” means Contractors Equipment, Materials, Plant and Temporary Works, or any of them as appropriate.“货物”系指承包商设备、材料、生产设备和临时工程，或视情况其中任何一种。1.1.5.3“Materials” means things of all kinds （other than Plant） intended t

30、o form or forming part of the Permanent Works, including the supply-only materials （if any） to be supplied by the Contractor under the Contract.“材料”系指拟构成或正构成永久工程一部分的各类物品（生产设备除外），包括根据合同要由承包商供应的只供材料（如果有）。1.1.5.4“Permanent Works” means the permanent works to be designed and executed by the Contractor under the Contract.“永久工程”系指根据合同承包商要进行设计和施工的永久性工程。1.1.5.5“Plant “means the apparatus, machinery and vehicles intended to form or forming part of the Permanent Works.“生产设备”系指拟构